Loading...
Serving St. Cloud, FL and surrounding areas. (689) 214-9067
Effective Date: January 1, 2026
By accessing or using the website located at stcloudsunroomsandpatios.com (the "Site") or by requesting services from Apex Point St Cloud Sunrooms ("we," "our," or "us"), you agree to be bound by these Terms and Conditions. If you do not agree to these terms, please do not use our Site or request our services.
These terms apply to all visitors, customers, and others who access or use the Site or engage our services.
Apex Point St Cloud Sunrooms is a sunroom contractor based in St. Cloud, FL. We provide sunroom additions, patio enclosures, screen room installation, and related residential construction services to homeowners in the St. Cloud area and surrounding Central Florida communities.
Services are performed at the customer's property under a written service agreement. No work begins until a written contract is signed by both parties and any required deposit is received.
We reserve the right to decline any project request at our discretion.
Estimates provided before a site visit are preliminary and non-binding. Final pricing is determined after an on-site assessment and is set forth in a written contract.
Written estimates are valid for 30 days from the date issued, unless otherwise stated. Prices are subject to change after that period due to changes in material costs, labor rates, or project scope.
Any changes to the agreed scope of work after a contract is signed must be documented in a written change order signed by both parties. Additional work not covered by the original contract will be billed at agreed rates.
Project start dates are estimates and are subject to permit approval timelines, material availability, and weather conditions. We will communicate scheduling updates to you throughout the process.
If you need to cancel or postpone a scheduled project, please notify us as soon as possible. Cancellation policies are set forth in your written contract. Deposits may be non-refundable depending on the stage of the project and costs already incurred.
We reserve the right to reschedule work due to weather conditions that make safe construction impossible. We will not charge additional fees for weather-related delays.
Payment terms are set forth in your written contract. In general, a deposit is required to secure your project start date, with additional installments due at specified milestones, and a final balance due upon completion.
Final payment is due upon project completion and satisfactory inspection. We reserve the right to charge interest on balances not paid within the timeframe specified in your contract.
Failure to make payments as agreed may result in a stop-work order. We reserve the right to place a lien on the property in accordance with Florida law if payment obligations are not met.
We obtain all required building permits on your behalf as part of the project. Permit fees are included in or added to your contract price as specified. Project timelines are contingent on permit approval, which is controlled by the applicable local government and is outside our control.
You agree to allow reasonable access to your property for scheduled inspections required by local building authorities.
Any warranty on workmanship or materials will be set forth in your written contract. Unless expressly stated in the contract, all warranties are limited in scope and duration.
Warranties do not cover damage caused by natural disasters, acts of God, improper use or maintenance, modifications made by third parties after project completion, or normal wear and tear.
The Site and any information on it are provided "as is" without warranties of any kind, express or implied, including but not limited to implied warranties of merchantability or fitness for a particular purpose.
To the fullest extent permitted by applicable law, Apex Point St Cloud Sunrooms shall not be liable for any indirect, incidental, consequential, special, or punitive damages arising from the use of our Site or services, including but not limited to loss of profits, loss of data, or business interruption.
Our total liability to you for any claim arising from our services shall not exceed the total amount paid by you for the specific services giving rise to the claim.
Some jurisdictions do not allow the exclusion of certain warranties or the limitation of liability for certain types of damages. In those jurisdictions, our liability is limited to the greatest extent permitted by law.
It is your responsibility to determine whether your property is subject to any homeowners association (HOA) rules, deed restrictions, or other covenants that may affect the design, placement, or appearance of any work we perform. We will work with you to design a project that meets known restrictions, but final approval from any HOA is your responsibility to obtain prior to work beginning.
You represent that you have the legal authority to authorize construction work on the property. You agree to provide reasonable access to your property during scheduled work hours and to disclose any known site conditions - such as underground utilities, drainage issues, or structural concerns - that may affect the project.
We are not responsible for pre-existing conditions at the property that were not disclosed prior to contract signing, or that were not reasonably discoverable during our site assessment.
In the event of a dispute arising from your use of our Site or from our services, both parties agree to first attempt to resolve the matter through good-faith negotiation. If negotiation is unsuccessful, either party may pursue mediation before initiating litigation.
Nothing in this section prevents either party from seeking injunctive or other equitable relief in a court of competent jurisdiction where necessary to prevent immediate and irreparable harm.
These Terms and Conditions are governed by and construed in accordance with the laws of the State of Florida, without regard to its conflict of law provisions. Any legal action or proceeding arising from these terms shall be brought exclusively in the courts located in Florida.
You agree not to use our Site for any unlawful purpose or in any way that could damage, disable, overburden, or impair the Site. You may not attempt to gain unauthorized access to any part of the Site or its related systems.
The content on this Site - including text, images, and other materials - is owned by Apex Point St Cloud Sunrooms and is protected by applicable copyright and intellectual property laws. You may not reproduce or distribute any content without our prior written consent.
We reserve the right to update or modify these Terms and Conditions at any time. When we do, we will update the effective date at the top of this page. Your continued use of our Site or services after any changes are posted constitutes your acceptance of the revised terms.
We encourage you to review this page periodically.
If you have questions about these Terms and Conditions, please contact us:
Apex Point St Cloud Sunrooms
1023 7th St
St. Cloud, FL 34769